Terms and Conditions
Effective date: 27 May 2026
This document applies to JARRETT PLATFORMS LTD, https://jarrettplatforms.technology, about@jarrettplatforms.technology, +447025756407, 118 Titsey Road, OXTED, RH8 0DF, United Kingdom.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. We maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. We may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
We warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. We do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. We retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. We may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
We implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. We indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
We may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
We may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.
4. Client Responsibilities
Client shall provide timely access to stakeholders, systems, documentation, and decision-makers necessary for delivery. Delays caused by Client unavailability may adjust schedules and fees. Client warrants it has rights to materials supplied to us and that use will not infringe third-party rights.
5. Fees and Payment
Fees are as stated in the SOW. Invoices are payable within thirty days unless otherwise agreed. Late payments may incur interest at 8% above Bank of England base rate under the Late Payment of Commercial Debts (Interest) Act 1998. As JARRETT PLATFORMS LTD, we may suspend Services for overdue accounts after notice.
6. Delivery and Acceptance
Deliverables are deemed accepted if Client does not provide written rejection with specific defects within ten business days of delivery notification, unless another period is specified. Rejected deliverables will be remedied within a reasonable period. Acceptance does not waive latent defects discovered through reasonable testing within the warranty period.
7. Warranty
As JARRETT PLATFORMS LTD, we warrant that Services will be performed with reasonable skill and care consistent with professional standards for custom computer programming and systems design. Software warranties are limited to correction of reproducible defects reported during the warranty period stated in the SOW. As JARRETT PLATFORMS LTD, we do not warrant uninterrupted operation of third-party platforms.
8. Intellectual Property
Unless otherwise agreed, Client receives a licence to use Deliverables for internal business purposes upon full payment. As JARRETT PLATFORMS LTD, we retain ownership of pre-existing tools, frameworks, libraries, and general know-how. Custom code ownership may be assigned by explicit SOW clause. As JARRETT PLATFORMS LTD, we may reuse non-confidential generic components.
9. Confidentiality
Each party shall protect Confidential Information using at least reasonable care, disclose only to personnel with need to know, and not use except for contract performance. Exclusions include public domain information, independently developed materials, and disclosures required by law with notice where permitted.
10. Data Protection
Where we process personal data on Client's behalf, a data processing agreement applies. Each party complies with UK GDPR obligations relevant to its role as controller or processor.
11. Security
As JARRETT PLATFORMS LTD, we implement security controls appropriate to the nature of Services, including secure coding practices, access management, and incident notification without undue delay where Client data is affected.
12. Limitation of Liability
Except for death, personal injury, fraud, or liabilities that cannot be limited by law, each party's aggregate liability arising under the contract is capped at fees paid in the twelve months preceding the claim. Neither party is liable for indirect or consequential loss including lost profits, except where unlawful to exclude.
13. Indemnity
Client indemnifies us against claims arising from Client materials or unlawful use of Deliverables. As JARRETT PLATFORMS LTD, we indemnify Client against claims that Deliverables infringe UK intellectual property rights, subject to prompt notice and control of defence.
14. Term and Termination
Either party may terminate for material breach not remedied within thirty days of notice. Either party may terminate for insolvency events. Upon termination, Client pays for work performed and committed costs. Provisions on confidentiality, IP, liability, and dispute resolution survive.
15. Force Majeure
Neither party is liable for delay caused by events beyond reasonable control including infrastructure failures, acts of government, natural disasters, or widespread cyber incidents, provided mitigation efforts are undertaken.
16. Subcontracting
As JARRETT PLATFORMS LTD, we may subcontract specialised tasks while remaining responsible for performance. Subcontractors handling personal data are bound by appropriate agreements.
17. Non-Solicitation
During engagement and for twelve months thereafter, parties shall not solicit each other's key personnel directly involved in delivery, except through general recruitment not targeted at specific individuals.
18. Publicity
As JARRETT PLATFORMS LTD, we may reference Client name and general project description in credentials unless Client opts out in writing. No confidential details are disclosed without approval.
19. Dispute Resolution
Parties shall attempt good faith negotiation, then mediation in London under CEDR rules if unresolved within thirty days. Litigation may proceed in England and Wales if mediation fails.
20. Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Exclusive jurisdiction lies with the courts of England and Wales.
1. Definitions
In these Terms and Conditions, "Client" means the party engaging JARRETT PLATFORMS LTD. "Services" means computer systems design, software development, integration, consulting, support, and related deliverables. "Deliverables" means code, documentation, configurations, and materials specified in a Statement of Work. "SOW" means the document describing scope, milestones, fees, and acceptance criteria. "Confidential Information" means non-public technical, commercial, or operational information disclosed by either party.
2. Contract Formation
A binding contract arises when a SOW or service agreement is signed by authorised representatives or when we confirm acceptance of a purchase order referencing these Terms. Preliminary discussions, proposals, and website content do not create binding obligations except as expressly stated.
3. Scope and Change Control
Services are delivered according to the agreed SOW. Client requests outside scope require a change request assessing impact on timeline, cost, and risk. No work on material scope changes begins without written approval. As JARRETT PLATFORMS LTD, we maintain traceability between requirements, design decisions, and delivery routes.